Citation Codes Equivalent Citations citation codes Attorney(S) Robert P. Walton, S. Andrew Schaffer Moira Morrissey for Frederick Cohen Charles Fastenberg for See more information ... Smart Summary Please sign up to generate summary. X.L.O. CONCRETE CORP., Plaintiff, v. JOHN T. BRADY AND COMPANY et al., Respondents. JOHN T. BRADY AND COMPANY, Third-Party Plaintiff-Respondent, Order affirmed, with costs, and question certified answered in the affirmative for so much of the reasons stated in the opinion by Justice Joseph P. Sullivan at the Appellate Division ( 104 A.D.2d 181) as holds that a liquidated damage provision in a construction contract is not vitiated by the owner's own culpability in causing some of the delay, and that in the situation here present the owner is limited to recovery of the stipulated sum. Concur: Chief Judge WACHTLER and Judges JASEN, MEYER, SIMONS and TITONE. Taking no part: Judges KAYE and ALEXANDER.