(1) The Authority shall prepare its annual report in Form ARA .
(2) The Authority may also include in the Annual Report such other matters as deemed fit by the Authority for reporting to the Government.
(3) The annual report shall, after adoption at a meeting of the Authority and signed by the Chairperson and Members and authenticated by affixing the common seal of the Authority, with requisite number of copies thereof, be submitted to the Government within a period of one hundred and eighty days immediately following the close of the financial year for which it has been prepared.
FORM REP-I
[See rule 3(1)]
APPLICATION FOR REGISTRATION OF PROJECT
To
The Real Estate Authority
Haryana______________
_____________________
Sir,
[I/We] hereby apply for the grant of registration of my/our project to be set up at_________ Tehsil ___________ District _________ State __________.
1. The requisite particulars are as under:
(i) Status of the applicant [individual/company/proprietorship firm/societies/partnership firm/competent authority etc.];
(ii) In case of individual
(a) Name
(b) Father's Name
(c) Occupation
(d) Address
(e) Contact Details (Phone number, E-mail, Fax Number etc.)
(f) Name, photograph, contact details and address of the promoter
OR
In case of [firm/societies/trust/companies/limited liability partnership/competent authority etc.]
(a) Name
(b) Address
(c) Copy of registration certificate
(d) Main objects
(e) Contact Details (Phone number, E-mail, Fax Number etc.)
(f) Name, photograph, contact details and address of [chairman/partners/directors] and authorised person etc.
(iii) PAN No. ________ of the promoter;
(iv) Name and address of the bank or banker with which account in terms of sub-clause (D) of clause (1) of subsection (2) of section 4 will be maintained ________;
(v) Details of project land held by the applicant ________;
(vi) brief details of the projects launched by the Promoter in the last five years, whether already completed or being developed, as the case may be, including the current status of the said projects, any delay in its completion, details of cases pending, details of type of land and payments pending etc. ________________________;
(vii) Agency to take up external development works _____ Local Authority/Self Development;
(viii) Registration fee by way of a demand draft/bankers cheque in favour of Haryana Real Estate Regulatory Authority dated ________drawn on ________________ bearing no. ______ for an amount of Rs. ____________/- calculated as per sub-rule (2) of rule 3 or through online payment as the case may be ________________ (give details of online payment such as date paid, transaction no. etc.);
(ix) Any other information the applicant may like to furnish.
2. [I/we] enclose the following documents in triplicate, namely:
(i) authenticated copy of the PAN card of the promoter;
(ii) annual report including the liability on the books of the builder, especially its debt to asset ratio, its audited profit and loss account, balance sheet, cash flow statement, directors report and the auditors report of the promoter for the immediately preceding three financial years and where annual report is not available, the audited profit and lost account, balance sheet, cash flow statement and the auditors report of the promoter for the immediately preceding three financial years or whatever period applicable in this regard;
(iii) authenticated copy of the legal title deed reflecting the title of the promoter to the land on which development of project is proposed along with legally valid documents for change of title with authentication of such title;
(iv) details of encumbrances on the land on which development of project is proposed including details of any rights, title, interest, dues, litigation and name of any party in or over such land or no encumbrance certificate from concerned revenue officer not below the rank of tehshildar;
(v) where the promoter is not the owner of the land on which development of project is proposed details of the consent of the owner of the land along with a copy of the registered (wherever applicable), collaboration agreement, development agreement, joint development agreement or any other agreement, as the case may be, entered into between the promoter and such owner and copies of title and other documents reflecting the title of such owner on the land on which project is proposed to be developed;
(vi) authenticated copy of the licence or land use permission, sanctioned building(s) plan and other sanctions from the competent authority obtained in accordance with the laws applicable and where the project is proposed to be developed in phases, an authenticated copy of the licence or land use permission, sanctioned layout plan/building(s) plan as the case may be for each of such phase(s);
(vii) authenticated copy of the site plan or site map showing the location of the project land along with names of revenue estates, survey numbers, cadastral numbers, khasra numbers and area of each parcels of the project land;
(viii) authenticated copy of the layout plan of the project or the phase(s) thereof, and also the layout plan of the whole project as sanctioned by the competent authority and other specifications of the project;
(ix) floor plans for each tower and block including clubhouse, amenities and common areas;
(x) any other permission, approval or sanction that may be required under applicable law including fire no-objection certificate, permission from water and sewerage department etc.;
(xi) authenticated copy of part completion/completion certificate, occupation certificate or part thereof
(xii) the plan of development works to be executed in the proposed project and the proposed facilities to be provided thereof including fire-fighting facilities, drinking water facilities, emergency evacuation services, use of renewable energy;
(xiii) the location details of the project, with clear demarcation of land dedicated for the project along with its boundaries including the latitude and longitude of the end points of the project;
(xiv) proforma of the allotment letter, agreement for sale, and the conveyance deed proposed to be signed with the Allottees;
(xv) the number, type and area of plots for sale alongwith the other amenities, facilities and services to be given in the said project.
(xvi) the number, type and the carpet area of apartments for sale in the project along with the area of the exclusive balcony or verandah areas and the exclusive open terrace areas apartment with the apartment, if any;
(xvii) the number and areas of parking space for sale in the project;
(xviii) the number of open parking areas and the number of covered parking areas available in the real estate project;
(xix) the names and addresses of his real estate agents, if any, for the proposed project;
(xx) the names and addresses of the contractors, architect, structural engineer, if any and other persons concerned with the development of the proposed project;
(xxi) a declaration in FORM REP-II.
3. [I/We] enclose the following additional documents and information regarding ongoing projects, as required under rule 4, and under other provisions of the Act or the rules and regulations made thereunder, namely.
(i)
(ii)
(iii)
4. [I/We] solemnly affirm and declare that the particulars given herein are correct to [my/our] knowledge and belief and nothing material has been concealed by [me/us] therefrom.
Dated:
Place:
Yours faithfully,
Signature and seal of the applicant(s)
FORM REP-II
[See rule 3(3)]
DECLARATION, SUPPORTED BY AN AFFIDAVIT, WHICH SHALL BE SIGNED BY THE PROMOTER OR ANY PERSON AUTHORIZED BY THE PROMOTER
Affidavit cum Declaration
Affidavit cum Declaration of Mr./Ms. ________________ promoter of the proposed project/duly authorized by the promoter of the proposed project, vide its/his/their authorization dated ______;
I, ________ [promoter of the proposed project/duly authorized by the promoter of the proposed project] do hereby solemnly declare, undertake and state as under:
1. That [I/promoter] [have/has] a legal title to the land on which the development of the project is proposed
Or
________________ [have/has] a legal title to the land on which the development of the proposed project is to be carried out
and
a legally valid authentication of title of such land along with an authenticated copy of the agreement between such owner and promoter for development of the real estate project is enclosed herewith.
Explanation. where the promoter is not the owner of the land on which development of project is proposed, details of the consent of the owner(s) of the land along with a copy of the registered (wherever applicable) collaboration agreement, development agreement, joint development agreement or any other agreement, as the case may be, entered into between the promoter and such owner and copies of title and other documents reflecting the title of such owner on the land on which project is proposed to be developed
2. That the said land is free from all encumbrances.
Or
That details of encumbrances ______________ including details of any rights, title, interest, dues, litigation and name of any party in or over such land.
3. That the time period within which the project shall be completed by [me/promoter] is ____________.
4. That seventy per cent of the amounts realised by [me/promoter] for the real estate project from the Allottees, from time to time, shall be deposited in a separate account to be maintained in a scheduled bank to cover the cost of construction and the land cost and shall be used only for that purpose.
5. That the amounts from the separate account, to cover the cost of the project, shall be withdrawn by [me/the promoter] in proportion to the percentage of completion of the project.
6. That the amounts from the separate account shall be withdrawn [me/the promoter] after it is certified by an engineer, an architect and a chartered accountant in practice that the withdrawal is in proportion to the percentage of completion of the project.
7. That [I/the promoter] shall get the accounts audited within six months after the end of every financial year by a chartered accountant in practice, and shall produce a statement of accounts duly certified and signed by such chartered accountant and it shall be verified during the audit that the amounts collected for a particular project have been utilised for the project and the withdrawal has been in compliance with the proportion to the percentage of completion of the project.
8. That [I/the promoter] shall take all the pending approvals on time, from the competent authorities.
9. That [I/the promoter] [have/has] furnished such other documents as have been prescribed by the Act and the rules and regulations made thereunder.
10. That [I/the promoter] shall not discriminate against any allottee at the time of allotment of any apartment, plot or building, as the case may be, on the grounds of sex, cast, creed, religion etc.
Deponent
Verification
The contents of my above Affidavit cum Declaration are true and correct and nothing material has been concealed by me therefrom.
Verified by me at ________on this ________day of _____________.
Deponent
FORM REP-III
[See rule 5(1)]
REGISTRATION CERTIFICATE OF PROJECT
This registration is granted under section 5 to the following project under project registration number ___________:
_______________________________________________________________
[Specify Details of Project including the project address];
1. (in the case of an individual) [Mr./Ms.] ________________________son of [Mr./Ms.] ________________________ Tehsil ________ District ________ State ________;
Or
[in the case of a firm/society/company/competent authority etc.] ________________ [firm/society/company/competent authority etc.] ________________ having its [registered office/principal place of business] at ________________.
2. This registration is granted subject to the following conditions, namely:
(i) The promoter shall enter into an agreement for sale with the allottees as prescribed by the Government;
(ii) The promoter shall offer to execute and register a conveyance deed in favour of the allottee or the association of the allottees, as the case may be, of the unit/apartment, plot or building as the case may be;
(iii) The promoter shall convey/allow usage of common areas as per Rule 2(1)(f) of the HRERA Rules, 2017.
(iv) The Promoter shall deposit seventy percent of the amounts realised by the Promoter in a separate account to be maintained in a schedule bank to cover the cost of construction and the land cost to be used only for that purpose as per sub-clause (D) of clause (1) of sub-section (2) of section 4;
(v) The registration shall be valid for a period of ______ years commencing from ________ and ending with ________________unless extended by the Authority in accordance with the Act and rules made thereunder;
(vi) The promoter shall comply with the provisions of the Acts and the rules and regulations made thereunder and applicable in the State;
(vii) The promoter shall not contravene the provisions of any other law for the time being in force as applicable to the project.
(viii) The promoter shall comply with all other terms and conditions as conveyed by the Authority.
3. If the above mentioned conditions are not fulfilled by the promoter, the Authority may take necessary action against the promoter including revoking the registration granted herein, as per the Act and the rules and regulations made thereunder.
Dated:
Place:
Signature and seal of the Authorized Officer
Real Estate Authority.
FORM REP-IV
[See rules 5(2), rule 6(3), rule 7]
INTIMATION OF REJECTION OF APPLICATION FOR REGISTRATION OF PROJECT/REJECTION OF APPLICATION FOR EXTENSION OF REGISTRATION OF PROJECT/REVOCATION OF REGISTRATION OF PROJECT
From:
The Real Estate Authority,
________________
________________
To
________________
________________
________________
Application/Registration No.: ________
Dated: ________
You are hereby informed that your application for registration of your project is rejected.
or
You are hereby informed that your application for extension of the registration of your project is rejected.
or
You are hereby informed that the registration granted to your project is hereby revoked.
for the reasons set out: ________________________________
Place:
Dated:
Signature and seal of the Authorized Officer
Real Estate Authority
FORM REP-V
[See rule 6(1)]
APPLICATION FOR EXTENSION OF REGISTRATION OF PROJECT
From:
________________
________________
________________
To
The Real Estate Authority,
________________
________________
________________
Sir,
[I/We] hereby apply for extension of registration of the following project:
_______________________________________________________________
_______________________________________________________________
registered with the Authority vide project registration certificate bearing No. ________________, which expires on ________________.
As required [I/we] submit the following documents and information, namely:
(i) A demand Draft No./Bankers Cheque No. ________ dated ________ for rupees________ in favour of in favour of Haryana Real Estate Regulatory Authority drawn on ________________ bank as extension fee as provided under sub rule (2) of rule 6 or through online payment as the case may be ________ (give details of online payment such as date paid, transaction no. etc.);
(ii) Authenticated Plan of the project showing the stage of development/construction works undertaken till date;
(iii) Explanatory note regarding the state of development/construction works in the project and reason for not completing the development works in the project within the period declared in the declaration submitted in Form REP-II at the time of making application for the registration of the project ________________________________;
(iv) Authenticated copy of the [permission/approval] from the competent authority which is valid for a period which is longer than the proposed term of extension of the registration sought from the Authority;
(v) The original project registration certificate; and
(vi) Any other information as may be specified by regulations.
Place:
Dated:
Yours faithfully,
Signature and seal of the applicant(s)
FORM REP-VI
[See rule 6(3)]
CERTIFICATE FOR EXTENSION OF REGISTRATION OF PROJECT
This extension of registration is granted under section 6 to the following project:_____________________________________________________________________, registered with the Authority vide project registration certificate bearing No. ________________ of:
1. [in the case of an individual] [Mr./Ms.] ________________________ son of [Mr./Ms.] ________________________ Tehsil ________ District________________ State ________________;
OR
[in the case of a firm/society/company/competent authority etc.] ________________ [firm/society/company/competent authority etc.] ________________having its [registered office/principal place of business] at ________________.
2. This extension of registration is granted subject to the following conditions, namely:
(i) The promoter shall offer to execute and register a conveyance deed in favour of the allottee(s) for Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage (as the case may be) alongwith parking (if applicable);
(ii) The promoter shall deposit seventy percent of the amounts realised by the promoter in a separate account to be maintained in a schedule bank to cover the cost of construction and the land cost to be used only for that purpose as per sub-clause (D) of clause (1) of sub-section (2) of section 4;
(iii) The registration shall be extended by a period of ________ [days/week/months] and shall be valid until ________;
(iv) The promoter shall comply with the provisions of the Act and the rules and regulations made thereunder;
(v) The promoter shall not contravene the provisions of any other law for the time being in force as applicable to the project;
(vi) If the above mentioned conditions are not fulfilled by the promoter, the Authority may take necessary action against the promoter including revoking the registration granted herein, as per the Act and the rules and regulations made there under.
Dated:
Place:
Signature and seal of the Authorized Officer
Real Estate Authority
FORM REA-I
[See rule 9(1)]
APPLICATION FOR REGISTRATION OF REAL ESTATE AGENT
To
The Real Estate Authority
________________
________________
Sir,
[I/We] apply for the grant of registration as a real estate agent to facilitate the sale or purchase of any plot, apartment or building, as the case may be, in real estate projects registered in the ________ State in terms of the Act and the rules and regulations made thereunder,
1. [in the case of an individual] [Mr./Ms.] ________________________ son of [Mr./Ms.] ________________________ Tehsil ________ District________________________ State ________________;
or
[in the case of a firm/society/company etc.] ________________ [firm/society/company etc.] ________________ having its [registered office/principal place of business] at ________________.
2. The requisite particulars are as under:
(i) Status of the applicant, whether [individual/company/proprietorship firm/societies/partnership firm/limited liability partnership etc.];
(ii) In case of individual
(a) Name of [Individual/Proprietorship firm]
(b) Father's Name
(c) Occupation
(d) Address
(e) Contact Details (Phone number, E-mail, Fax Number etc.)
(f) Name, photograph, contact details and address of the promoter or
In case of [firm/societies/company etc]
(a) Name
(b) Address
(c) Copy of registration certificate as [firm/societies/company etc.]
(d) Major activities
(e) Contact Details (Phone number, E-mail, Fax Number etc.)
(f) Name, photograph, contact details and address of [partners/directors etc.] and authorised person etc.
(iii) Particulars of registration as [proprietorship, societies, partnership, company etc.] including the bye-laws, memorandum of association, articles of association etc. as the case may be;
(iv) Authenticated copy of the address proof of the place of business;
(v) Details of registration in any other State or Union Territory;
(vi) Any other information as specify by regulations.
3. [I/we] enclose the following documents along with, namely:
(i) Demand Draft/Bankers Cheque No. ________ dated ________ for a sum of Rs. ________, in favour of Haryana Real Estate Regulatory Authority ________, drawn on ________________ bank as registration fee as per sub-rule (2) of rule 9 or through online payment as the case may be ________________ (give details of online payment such as date paid, transaction no. etc.);
(ii) authenticated copy of the PAN card of the real estate agent; and
(iii) authenticated copy of the registration as a real estate agent in any other State or Union Territory, if applicable;
4. [I/we] solemnly affirm and declare that the particulars given in herein are correct to [my/our] knowledge and belief and nothing material has been concealed by [me/us] therefrom.
Dated:
Place:
Yours faithfully,
Signature and seal of the applicant(s)
FORM REA-II
[See rule 10(2)]
REGISTRATION CERTIFICATE OF REAL ESTATE AGENT
1. This registration is granted under section 9 with registration certificate bearing No. ________ to
[in the case of an individual] [Mr./Ms.] ________________________ son of [Mr./Ms.] ________________ Tehsil ________ District________________________ State ________________;
or
[in the case of a firm/society/company etc.] ________ [firm/society/company etc.] ________ having its [registered office/principal place of business] at ________.
to act as a real estate agent to facilitate the sale or purchase of any plot/unit/apartment or building, as the case may be, in real estate projects registered in the ________ State in terms of the Act and the rules and regulations made thereunder,
2. This registration is granted subject to the following conditions, namely:
(i) The real estate agent shall not facilitate the sale or purchase of any plot, apartment or building, as the case may be, in a real estate project or part of it, being sold by the promoter which is required but not registered with the Authority;
(ii) The real estate agent shall maintain and preserve such books of account, records and documents as provided under rule 12;
(iii) The real estate agent shall not involve himself in any unfair trade practices as specified under clause (c) of section 10;
(iv) The real estate agent shall facilitate the possession of all information and documents, as the allottee is entitled to, at the time of booking of any plot, apartment or building, as the case may be;
(v) The real estate agent shall provide assistance to enable the allottee and promoter to exercise their respective rights and fulfil their respective obligations at the time of booking and sale of any plot, apartment or building, as the case may be.
(vi) The real estate agent shall comply with the provisions of the Act and the rules and regulations made thereunder;
(vii) The real estate agent shall not contravene the provisions of any other law for the time being in force as applicable to him;
(viii) The real estate agent shall discharge such other functions as may be specified by the Authority by regulations;
3. The registration is valid for a period of five years commencing from ________ and ending with ________________ unless renewed by the Authority in accordance with the provisions of the Act or the rules and regulations made thereunder.
4. If the above mentioned conditions are not fulfilled by the real estate agent, the Authority may take necessary action against the real estate agent including revoking the registration granted herein, as per the Act and the rules and regulations made thereunder.
Dated:
Place:
Signature and seal of the Authorized Officer
Real Estate Authority
FORM REA-III
[See rule 10(3), 11(4), 12]
INTIMATION OF REJECTION OF APPLICATION FOR REGISTRATION OF REAL ESTATE AGENT/REJECTION OF APPLICATION FOR RENEWAL OF REGISTRATION OF REAL ESTATE AGENT/REVOCATION OF REGISTRATION OF REAL ESTATE AGENT
From:
The Real Estate Authority,
________________
________________
To
________________
________________
________________
Application/Registration No.: ________________
Dated: ________________
You are hereby informed that your application for registration as real estate agent is rejected.
or
You are hereby informed that your application for the renewal of the registration as real estate agent is rejected.
or
You are hereby informed that the registration granted to you as real estate agent is hereby revoked.
for the reasons set out: ________________________________
Place:
Dated:
Signature and seal of the Authorized Officer
Real Estate Authority
FORM REA-IV
[See rule 11(1)]
APPLICATION FOR RENEWAL OF REGISTRATION OF REAL ESTATE AGENT
From:
________________
________________
________________
To
The Real Estate Authority,
________________
________________
________________
Sir,
[I/we] apply for renewal my/our registration as a real estate agent under registration certificate bearing No. ________, which expires on ________.
As required [I/we] submit the following documents and information, namely:
(i) A demand draft/bankers cheque no. ________ dated ________ for rupees ________ in favour of Haryana Real Estate Regulatory Authority ________ drawn on ________________________ bank as renewal fee as per sub-rule (2) of rule 11 or through online payment as the case may be ________ (give details of online payment such as date paid, transaction no. etc.);
(ii) The authenticated copy of the registration certificate; and
(iii) Status of the applicant, whether [individual/company/proprietorship firm/societies/partnership firm/limited liability partnership etc.];
(iv) In case of individual
(a) Name of [Individual/Proprietorship Firm]
(b) Father's Name
(c) Occupation
(d) Address
(e) Contact Details (Phone number, E-mail, Fax Number etc.)
(f) Name, photograph, contact details and address of the proprietor or
In case of [firm/societies/company etc.]
(a) Name
(b) Address
(c) Copy of registration certificate as [firm/societies/company etc.]
(d) Major activities
(e) Contact Details (Phone number, E-mail, Fax Number etc.)
(f) Name, photograph, contact details and address of [partners/directors etc.].
(v) particulars of registration as [proprietorship, societies, partnership, company etc.] including the bye-laws, memorandum of association, articles of association etc. as the case may be;
(vi) authenticated copy of the address proof of the place of business;
(vii) authenticated copy of the PAN Card of the real estate agent;
(viii) authenticated copy of the registration as a real estate agent in any other State or Union Territory, if applicable;
(ix) any other information as specified by regulations;
2. [I/We] solemnly affirm and declare that the particulars given in herein are correct to [my/our] knowledge and belief and nothing material has been concealed by [me/us] therefrom.
Dated:
Place:
Yours faithfully,
Signature and seal of the applicant(s)
FORM REA-V
[See rule 11(4)]
RENEWAL OF REGISTRATION OF REAL ESTATE AGENT
1. This renewal of registration is granted under section 9 of the Act to
[in the case of an individual] [Mr./Ms.] ________________________ son of [Mr./Ms.] ________________________ Tehsil ________________ District________________ State ________________;
or
[in the case of a firm/society/company etc.] ________ [firm/society/company etc.] ________________ having its [registered office/principal place of business] at ________.
in continuation to registration certificate bearing No. ________________, of ________.
2. This renewal of registration is granted subject to the following conditions, namely:
(i) The real estate agent shall not facilitate the sale or purchase of any plot, apartment or building, as the case may be, in a real estate project or part of it, being sold by the promoter which is required but not registered with the Authority;
(ii) The real estate agent shall maintain and preserve such books of account, records and documents as provided under rule 13;
(iii) The real estate agent shall not involve himself in any unfair trade practices as specified under clause (c) of section 10;
(iv) The real estate agent shall facilitate the possession of all information and documents, as the allottee is entitled to, at the time of booking of any plot, apartment or building, as the case may be.
(v) The real estate agent shall provide assistance to enable the allottee and promoter to exercise their respective rights and fulfil their respective obligations at the time of booking and sale of any plot, apartment or building, as the case may be.
(vi) The real estate agent shall comply with the provisions of the Act and the rules and regulations made thereunder;
(vii) The real estate agent shall not contravene the provisions of any other law for the time being in force as applicable to him;
(viii) The real estate agent shall discharge such other functions as may be specified by the Authority by regulations;
3. The registration is valid for a period of five years commencing from ________ and ending with ________________ unless renewed by the Authority in accordance with the provisions of the Act or the rules and regulations made thereunder.
4. If the above mentioned conditions are not fulfilled by the real estate agent, the Authority may take necessary action against the real estate agent including revoking the registration granted herein, as per the Act and the rules and regulations made thereunder.
Dated:
Place:
Signature and seal of the Authorized Officer
Real Estate Authority
FORM AAT
[See rule 22(1)]
APPEAL TO APPELLATE TRIBUNAL
For use of Appellate Tribunal's office:
Date of filing: ________________
Date of [receipt at the filing counter of the Registry/receipt by post/online filing]: ________________
Appeal No.: ________________
Signature: ________________
Registrar: ________________
IN THE REAL ESTATE APPELLATE TRIBUNAL (Name of place)
Between
________________Appellant(s)
And
________________Respondent(s)
Details of appeal:
1. Particulars of the appellants:
(i) Name(s) of the appellant:
(ii) Address of the existing office/residence of the appellant:
(iii) Address for service of all notices:
(iv) Contact Details (Phone number, e-mail, Fax Number etc.):
2. Particulars of the respondents:
(i) Name(s) of respondent:
(ii) Office address of the respondent:
(iii) Address for service of all notices:
(iv) Contact Details (Phone number, e-mail, Fax Number etc.):
3. Jurisdiction of the Appellate Tribunal:
The appellant declares that the subject matter of the appeal falls within the jurisdiction of the Appellate Tribunal.
4. Limitation:
The appellant declares that the appeal is within the limitation specified in sub-section (2) of section 44
or
If the appeal is filed after the expiry of the limitation period specified under sub-section (2) of section 44 specify reasons for delay________________________
5. Facts of the case:
(give a concise statement of facts and grounds of appeal against the specific order of Authority or the)
Adjudicating Officer, as the case may be, passed under section(s) ________ or rule(s) ________ or regulation(s) ________).
6. Relief(s) sought:
In view of the facts mentioned in paragraph 5 above, the appellant prays for the following relief(s) ________________________.
[Specify below the relief(s) sought explaining the grounds of relief(s) and the legal provisions (if any) relied upon]
7. Interim order, if prayed for:
Pending final decision on the appeal the appellant seeks issue of the following interim order: [Give here the nature of the interim order prayed for with reasons]
8. Matter not pending with any other court, etc.:
The appellant further declares that the matter regarding which this appeal has been made is not pending before any court of law or any other authority or any other tribunal(s).
9. Particulars of [demand draft/bankers cheque or online payment] in respect of the fee in terms of sub-rule (2) of rule 22:
(i) Amount:
(ii) Name of the bank on which drawn:
(iii) [Demand draft number/bankers cheque/online payment transaction No.]:
10. List of enclosures:
(i) An attested true copy of the order against which the appeal is filed
(ii) Copies of the documents relied upon by the appellant and referred to in the appeal
(iii) An index of the documents
(iv) Other documents as annexed along with the complaint
Signature of the appellant(s)
Verification
I ________ (name in full block letters) [son/daughter] of ______ the appellant do hereby verify that the contents of paragraphs [1 to 10] are true to my personal knowledge and belief and that I have not suppressed any material fact(s).
Place:
Date:
Signature of the appellant(s)
Instructions. (1) Every appeal shall be filed in English and in case it is in some other Indian language, it shall be accompanied by a copy translated in English and shall be fairly and legibly type-written, lithographed or printed in double spacing on one side of standard petition paper with an inner margin of about four centimeters width on top and with a right margin on 2.5 cm, and left margin of 5 cm, duly paginated, indexed and stitched together in paper book form.
(2) Every appeal shall be presented along with an empty file size envelope bearing full address of the respondent and where the number of respondents are more than one, then sufficient number of extra empty file size envelopes bearing full address of each respondent shall be furnished by the party preferring the appeal.
FORM CRA
[See rule 28(1)]
COMPLAINT TO AUTHORITY
For use of Regulatory Authority(s) Office:
Date of filing: ________________
Date of [receipt at the filing counter of the Registry/receipt by post/online filing]: ________________
Complaint No.: ________________
Signature: ________________
Registrar: ________________
IN THE REGULATORY AUTHORITIES OFFICE (Name of place)
Between
________________Complainant(s)
And
________________Respondent(s)
Details of claim:
1. Particulars of the complainant(s):
(i) Name(s) of the complainant:
(ii) Address of the existing office/residence of the complainant:
(iii) Address for service of all notices:
(iv) Contact Details (Phone Number, e-mail, Fax Number etc.):
2. Particulars of the respondents:
(i) Name(s) of respondent:
(ii) Office address of the respondent:
(iii) Address for service of all notices:
(iv) Contact Details (Phone Number, e-mail, Fax Number etc.):
3. Jurisdiction of the Authority:
The complainant declares that the subject matter of the claim falls within the jurisdiction of the Authority.
4. Facts of the case:
[give a concise statement of facts and grounds for complaint]
5. Relief(s) sought:
In view of the facts mentioned in paragraph 4 above, the complainant prays for the following relief(s) ________________________________
[Specify below the relief(s) claimed explaining the grounds of relief(s) and the legal provisions (if any) relied upon]
6. Interim order, if prayed for:
Pending final decision on the complaint, the complainant seeks issue of the following interim order: [Give here the nature of the interim order prayed for with reasons]
7. Complainant not pending with any other court, etc.:
The complainant further declares that the matter regarding which this complaint has been made is not pending before any court of law or any other authority or any other tribunal(s).
8. Particulars of [demand draft/bankers cheque or online payment] in respect of the fee in terms of sub-rule (1) of rule 28:
(i) Amount
(ii) Name of the bank on which drawn
(iii) [Demand draft Number/bankers cheque/online payment transaction No.]
9. List of enclosures:
(i) Copies of the documents relief upon by the complainant and referred to in the complaint.
(ii) An index of documents.
(iii) Other documents as annexed along with complaint.
Signature of the complainant(s)
Verification
I ________ (name in full block letters) [son/daughter] of ______ the complainant do hereby verify that the contents of paragraphs [1 to 9] are true to my personal knowledge and belief and that I have not suppressed any material fact(s).
Place:
Date:
Signature of the complainant(s)
Instructions. (1) Every complaint shall be filed in English and in case it is in some other Indian language, it shall be accompanied by a copy translated in English and shall be fairly and legibly type-written, lithographed or printed in double spacing on one side of standard petition paper with an inner margin of about four centimeters width on top and with a right margin on 2.5 cm, and left margin of 5 cm, duly paginated, indexed and stitched together in paper book form.
(2) Every complaint shall be presented along with an empty file size envelope bearing full address of the respondent and where the number of respondents are more than one, then sufficient number of extra empty file size envelopes bearing full address of each respondent shall be furnished by the party preferring the complaint.
FORM CAO
[See rule 29(1)]
COMPLAINT TO ADJUDICATING OFFICER
Claim for interest and compensation under section 31 read with section 71
For use of Adjudicating Officers office:
Date of filing: ________________
Date of [receipt at the filing counter/receipt by post/online filing]: ________________
Complaint No.: ________________
Signature: ________________
Authorised Officer: ________________
IN THE ADJUDICATING OFFICERS OFFICE (Name of place)
Between
________________Complaint (s)
And
________________Respondent(s)
Details of claim:
Particulars of the complainant(s):
(i) Name(s) of the complainant:
(ii) Address of the existing office/residence of the complainant:
(iii) Address for service of all notices:
(iv) Contact Details (Phone Number, e-mail, Fax Number etc.):
(v) Details of allottees apartment, plot or building, as the case may be:
2. Particulars of the respondents:
(i) Name(s) of respondent:
(ii) Office address of the respondent:
(iii) Address for service of all notices:
(iv) Contact Details (Phone Number, e-mail, Fax Number etc.):
(v) Registration no. and address of project:
3. Jurisdiction of the Adjudicating Officer:
The complainant declares that the subject matter of the claim falls within the jurisdiction of the Adjudicating Officer.
4. Facts of the case:
[give a concise statement of facts and grounds of claim against the Promoter]
5. Compensation(s) sought:
In view of the facts mentioned in paragraph 4 above, the complainant prays for the following compensation(s) ________________________________
[Specify below the compensation(s) claimed explaining the grounds of claim(s) and the legal provisions (if any) relied upon]
6. Claim not pending with any other court, etc.:
The complainant further declares that the matter regarding which this complaint has been made is not pending before any court of law or any other authority or any other tribunal(s).
7. Particulars of [demand draft/bankers cheque or online payment] in respect of the fee in terms of sub-rule (1) of rule 29:
(i) Amount
(ii) Name of the bank on which drawn
(iii) [Demand draft number/bankers cheque or online payment transaction No.]
8. List of enclosures:
(i) Copies of the documents relief upon by the complainant and referred to in the complaint.
(ii) An index of documents.
(iii) Other documents as annexed along with complaint.
Signature of the complainant(s)
Verification
I ________ (name in full block letters) [son/daughter] of _______ he complainant do hereby verify that the contents of paragraphs [1 to 8] are true to my personal knowledge and belief and that I have not suppressed any material fact(s).
Place:
Date:
Signature of the complainant(s)
Instructions. (1) Every complaint shall be filed in English and in case it is in some other Indian language, it shall be accompanied by a copy translated in English and shall be fairly and legibly type-written, lithographed or printed in double spacing on one side of standard petition paper with an inner margin of about four centimeters width on top and with a right margin on 2.5 cm, and left margin of 5 cm, duly paginated, indexed and stitched together in paper book form.
(2) Every complaint shall be presented along with an empty file size envelope bearing full address of the respondent and where the number of respondents are more than one, then sufficient number of extra empty file size envelopes bearing full address of each respondent shall be furnished by the party preferring the complaint.
FORM ASA
[See rule 30(1)]
ANNUAL STATEMENT OF ACCOUNTS
Receipts and Payments Account
For the year ended________________
(In Rupees)
| A/c Code |
Receipts |
Current Year As on |
Previous year As on |
A/c Code |
Payments |
Current Year As on |
Previous year As on |
| 1. |
Balance Brought down: |
|
|
13. |
Chairperson and Members: |
|
|
| 1.1. |
Bank |
|
|
13.1. |
Pay and Allowances |
|
|
| 1.2. |
Cash in hand |
|
|
13.2. |
Other benefits |
|
|
| 2. |
Fee, Charges and Fine: |
|
|
13.3. |
Travelling expenses: |
|
|
| 2.1. |
Fees |
|
|
13.3.1 |
Overseas |
|
|
| 2.2. |
Charges |
|
|
13.3.2 |
Domestic |
|
|
| 2.3. |
Fines |
|
|
14. |
Officers: |
|
|
| 2.4. |
Others (specify) |
|
|
14.1. |
Pay and Allowances |
|
|
| 3. |
Grants: |
|
|
14.2. |
Retirement benefits |
|
|
| 3.1. |
To Accounts with Government |
|
|
14.3. |
Other benefits |
|
|
| 3.2. |
Others (specify) |
|
|
14.4. |
Travelling expenses: |
|
|
| 4. |
Gifts |
|
|
14.4.1 |
Overseas |
|
|
| 5. |
Seminars and conferences |
|
|
14.4.2 |
Domestic |
|
|
| 6. |
Sale of Publications |
|
|
15. |
Staff: |
|
|
| 7. |
Income on Investments and Deposits: |
|
|
15.1. |
Pay and Allowances |
|
|
| 7.1. |
Income on Investments |
|
|
15.2. |
Retirement benefits |
|
|
| 7.2. |
Income on Deposits |
|
|
15.3. |
Other benefits |
|
|
| 8. |
Loans: |
|
|
15.4. |
Travelling expenses: |
|
|
| 8.1. |
Government |
|
|
15.4.1 |
Overseas |
|
|
| 8.2. |
Others (specify) |
|
|
15.4.2 |
Domestic |
|
|
| 9. |
Sale of Assets |
|
|
16. |
Hire of Conveyance |
|
|
| 10. |
Sale on Investments |
|
|
17. |
Wages |
|
|
| 11. |
Recoveries from pay bills |
|
|
18. |
Overtime |
|
|
| 11.1 |
Loans and Advances Principal Amount |
|
|
19. |
Honorarium |
|
|
| 11.2 |
Interest on Loans and Advances |
|
|
20. |
Other office Expenses |
|
|
| 11.3 |
Miscellaneous |
|
|
21. |
Expenditure on Research |
|
|
| 51 |
Others (specify) |
|
|
22. |
Consultation expenses |
|
|
| |
|
|
|
23. |
Seminars and Conferences |
|
|
| |
|
|
|
24. |
Publications of Authority |
|
|
| |
|
|
|
25. |
Rent and Taxes |
|
|
| |
|
|
|
26. |
Interest on Loans |
|
|
| |
|
|
|
27. |
Promotional Expenses |
|
|
| |
|
|
|
28. |
Membership fee |
|
|
| |
|
|
|
29. |
Subscription |
|
|
| |
|
|
|
30. |
Purchase of Fixed Assets (specify) |
|
|
| |
|
|
|
31. |
Investments and Deposits: |
|
|
| |
|
|
|
31.1 |
Investments |
|
|
| |
|
|
|
31.2 |
Deposits |
|
|
| |
|
|
|
32. |
Security Deposits |
|
|
| |
|
|
|
33. |
Loans and Advances to: |
|
|
| |
|
|
|
33.1 |
Employees: |
|
|
| |
|
|
|
33.1.1 |
Bearing Interest |
|
|
| |
|
|
|
33.1.2 |
Not bearing Interest |
|
|
| |
|
|
|
33.2. |
Suppliers/contractors |
|
|
| |
|
|
|
33.3. |
Others (specify) |
|
|
| |
|
|
|
34. |
Repayment of loan |
|
|
| |
|
|
|
35. |
Others |
|
|
| |
|
|
|
35.1. |
Leave Salary and Pension |
|
|
| |
|
|
|
35.2. |
Contribution |
|
|
| |
|
|
|
35.3. |
Audit Fee |
|
|
| |
|
|
|
35.4. |
Misc: |
|
|
| |
|
|
|
36. |
Balance carried down: |
|
|
| |
|
|
|
36.1 |
Bank |
|
|
| |
|
|
|
36.2 |
Cash in hand |
|
|
| |
Total |
|
|
|
Total |
|
|
Chairperson (Signature)
Member(s) (Signature)
Secretary (Signature)
Office In-charge (Finance and Accounts)
Income and Expenditure Account
For the period 1st __________ to 31st_______________
(In Rupees)
| A/c Code |
Expenditure |
Schedule Current Year As on |
Previous Year As on |
A/c Code |
Income |
Schedule Current Year As on |
Previous Year As on |
| 13. |
Chairperson and Members |
|
|
2. |
Fee, Charges and Fine |
A. |
|
| 13.1 |
Pay and Allowances |
2.1 |
Fee |
| 13.2 |
Other benefits |
C. |
|
|
Charges |
|
|
| 13.3 |
Travelling Expenses |
|
|
2.3 |
Fines |
|
|
| 13.3.1 |
Overseas |
|
|
2.4 |
Others (specify) |
B. |
|
| 13.3.2 |
Domestic |
3. |
Grants |
| 14. |
Officers |
D |
|
3.1 |
Account with Govt. |
|
|
| 14.1 |
Pay and Allowances |
3.2 |
Others (Specify) |
| 14.2 |
Retirement Benefits |
4. |
Gifts |
| 14.3 |
Other Benefits |
C |
|
5. |
Seminars and Conferences |
|
|
| 14.4 |
Traveling Expenses |
6. |
Sale of Publications |
| 14.4.1 |
Overseas |
7. |
Income on investments and Deposits |
| 14.4.2 |
Domestic |
7.1 |
Income on investments |
| 15. |
Staff |
7.2 |
Income on Deposits |
| 15.1 |
Pay and Allowances |
11.2 |
Interest on Loan and Advances |
| 15.2 |
Retirement Benefits |
D |
|
12. |
|
|
|
| 15.3 |
Other Benefits |
C |
|
12.1 |
Gain on Sales of Assets |
|
|
| 15.4 |
Traveling expenses |
|
|
|
Excess of expenditure over income |
|
|
| 15.4.1 |
Overseas |
|
|
|
|
|
|
| 15.4.2 |
Domestic |
|
|
|
|
|
|
| 16. |
Hire of Conveyance |
|
|
|
|
|
|
| 17. |
Wages |
|
|
|
|
|
|
| 18. |
Overtime |
|
|
|
|
|
|
| 19. |
Honorarium |
|
|
|
|
|
|
| 20. |
Other office expenses |
E |
|
|
|
|
|
| 21. |
Expenditure on Research |
|
|
|
|
|
|
| 22. |
Consultation Expenses |
|
|
|
|
|
|
| 23. |
Seminars and conferences |
|
|
|
|
|
|
| 24. |
Publications of Authority |
|
|
|
|
|
|
| 25. |
Rent and Taxes |
|
|
|
|
|
|
| 26. |
Interest on loans |
|
|
|
|
|
|
| 27. |
Promotional Expenses |
|
|
|
|
|
|
| 28. |
Membership Fee |
F |
|
|
|
|
|
| 29. |
Subscription |
G |
|
|
|
|
|
| 35. |
Others |
|
|
|
|
|
|
| 35.1 |
Leave Salary and Pension |
|
|
|
|
|
|
| 35.2 |
Contribution |
|
|
|
|
|
|
| 35.3 |
Audit Fee |
|
|
|
|
|
|
| 35.4 |
Miscsellaneous |
|
|
|
|
|
|
| 37. |
Depreciation |
H |
|
|
|
|
|
| 48. |
Loss on sale of assets |
|
|
|
|
|
|
| 49. |
Bad Debts written off |
|
|
|
|
|
|
| 50. |
Provision for bad and doubtful debts |
|
|
|
|
|
|
| |
Excess of income over Expenditure |
|
|
|
|
|
|
| |
(Transferred to capital Fund Account) |
|
|
|
|
|
|
| |
Total |
|
|
|
Total |
|
|
Chairperson (Signature)
Member(s) (Signature)
Secretary (Signature)
Office In-charge (Finance and Accounts)
Balance Sheet as on 31st March_________
| A/c Code |
Liabilities |
Schedule |
Current Year as on |
Previous Year as on |
A/c Code |
Assets |
Schedule |
Current Year as on |
Previous Year as on |
| 40. |
Funds |
1 |
|
|
43. |
Fixed Assets |
H |
|
|
| 40.1 |
Capital Fund |
|
|
|
43.1 |
Gross Block at Cost |
|
|
|
| |
Add Excess of Income over Expenditure/less excess of Expenditure over Income |
|
|
|
|
Less Cumulative depreciation |
|
|
|
| 40.2 |
Other Funds (Specify) |
|
|
|
42.2 |
Net Block |
|
|
|
| 41. |
Reserves |
J |
|
|
44. |
Capital Work-in-progress |
M |
|
|
| 8. |
Loans |
K |
|
|
31. |
Investments & Deposits |
N |
|
|
| 8.1 |
Government |
|
|
|
31.1 |
Investment |
|
|
|
| 8.2 |
Others |
|
|
|
31.2 |
Deposits |
|
|
|
| 42. |
Current Liabilities and provisions |
L |
|
|
33. |
Loans and Advances |
O |
|
|
| |
|
|
|
|
3.1 |
Account with Government |
S |
|
|
| |
|
|
|
|
45. |
Sundry Debtors |
p |
|
|
| |
|
|
|
|
36. |
Cash and Bank Balances |
Q |
|
|
| |
|
|
|
|
46. |
Other Current Assets |
R |
|
|
| |
Total |
|
|
|
|
Total |
|
|
|
| |
Accounting policies and Notes to |
T |
|
|
|
|
|
|
|
Instructions. (1) The schedules referred/referenced above shall be prepared by the Authority based on accounting principles followed by the Government or by other regulatory authorities or as suggested by the Comptroller and Auditor General of India from time to time.
(2) The Schedules referred to above shall form an integral part of the Income and Expenditure Account or the Balance Sheet, as the case may be.
Chairperson (Signature)
Member(s) (Signature)
Secretary (Signature)
Office In-charge (Finance and Accounts)
FORM ARA
[See rule 31(1)]
ANNUAL REPORT TO BE PREPARED BY AUTHORITY
A. Introduction:
(i) Chairman's Statement:
(ii) Objectives:
(iii) Important Achievements:
(iv) The year in review:
a. Landmark decisions:
b. Legislative work:
c. Outreach programme:
(v) Capacity building:
(vi) International engagements:
(vii) Impact on:
a. Allottees:
b. Promoters:
c. Real Estate Agents:
d. Economy
B. Registration of promoters and real estate agents under the Act:
I. In relation to Promoters:
| Serial Number |
Name of Promoter |
Address of Promoter |
Description of project for which registration has been issued |
Fee paid |
Registration Number |
| 1 |
2 |
3 |
4 |
5 |
6 |
| |
|
|
|
|
|
| Date of issue of registration |
Date on which registration expires |
Date of extension of registration with period of extension |
Remark |
| 7 |
8 |
9 |
10 |
| |
|
|
|
II. In Relation to Real Estate Agents:
| Serial Number |
Name of Real Estate Agent |
Address of Real Estate Agent |
Registration Fee paid |
Registration No. |
Date of issue of Registration Certificate |
Date on which Registration Certificate Expires |
Date and period of renewal of registration certificate |
Remark |
| 1 |
2 |
3 |
4 |
5 |
6 |
7 |
8 |
9 |
| |
|
|
|
|
|
|
|
|
C. Number of cases filed before the Authority and the Adjudicating Officer for settlement of disputes and number of cases disposed.
| Sl. No. |
No. of Cases pending in the last quarter with the Authority |
No. of Cases received during the quarter by the Authority |
No. of Cases disposed of by the Authority |
| Sl. No. |
No. of cases pending in the last quarter with the adjudicating officer |
No. of cases received during the quarter by the adjudicating officer |
No. of cases disposed of by the adjudicating officer |
| |
|
|
|
D. Statement on the periodical survey conducted by the Authority to monitor the compliance of the provisions of the Act by the promoters, allottees and real estate agents.
| Sl. No. |
Survey conducted during the quarter with details |
Observation of Authority |
Remedial steps taken |
| |
|
|
|
E. Statement on steps taken to mitigate any non-compliance of the provisions of the and the rules and regulations made thereunder by the Promoters, Allottees and real estate agents.
| Sl. No. |
Subject |
Steps taken |
Results achieved |
| |
|
|
|
F. Statements on direction of the Authority and the penalty imposed for contraventions of the Act and the rules and regulations made thereunder and statement on interest and compensation ordered by the adjudicating officer:
| Sl. No. |
Name of the Promoter |
Details of the directions issued by the Authority/Adjudicating Officer |
Penalty/interest/compensations imposed |
Whether paid |
| |
|
|
|
|
| Sl. No. |
Name of the Allottee |
Details of the directions issued by the Authority/adjudicating officer |
Penalty/interest/compensations imposed |
Whether paid |
| |
|
|
|
|
| Sl. No. |
Name of the real estate agent |
Details of the directions issued by the Authority/adjudicating officer |
Penalty/interest/compensations imposed |
Whether paid |
| |
|
|
|
|
G. Investigations and inquiries ordered by the Authority or the adjudicating officer: A brief narrative of investigations and inquiries taken up by the Authority or the adjudicating officers and references received from the competent authority or the Government.
H. Orders passed by the Authority and the adjudicating officer: A brief narrative of orders passed by the Authority or the adjudicating officers separately for where no offence is made out, and in case offence is proved, category-wise for each category of orders passed along with a tabular statement indicating the sections under which the order was passed and brief particulars of the orders.
I. Execution of the orders of the Authority and imposition of penalties: (i) monetary penalties - details of recovery of penalty imposed, details of penalty imposed but not recovered, total number of matters and total amount of monetary penalty levied, (ii) matters referred to court under section 59 - total number of matters referred to the court during the year, total number of matters disposed of by the court during the year, total number of matters pending with the court at the end of the year; (iii) matters referred to court for execution of order under section 40 - total number of matters referred to the court during the year, total number of matters disposed of by the court during the year, total number of matters pending with the court at the end of the year.
J. Execution of the orders of the adjudicating officer and imposition of interest and compensation: (i) interest and compensations - details of interest and compensation imposed, details of interest and compensation imposed but not paid, total number of matters and total amount of interest and compensations imposed and (ii) matters referred to court for execution of order under section 40 - total number of matters referred to the court during the year, total number of matters disposed of by the court during the year, total number of matters pending with the court at the end of the year.
K. Appeals:
(i) Number of appeals filed against the orders of the Authority or the adjudicating officer in the year:
(ii) Number of appeals pending at the beginning of the year:
(iii) Appeals filed during the year:
(iv) Number of appeals allowed by the Appellate Tribunal during the year:
(v) Number of appeals disallowed by the Appellate Tribunal during the year:
(vi) Brief write up on the appeals allowed by the Appellate Tribunal:
L. References received from the Government under section 33: a brief narrative on references received from the Government under section 33 providing for - number of references received during the year, number of references disposed of during the year, number of references pending at the end of the year.
M. Advocacy measures under sub-section (3) of section 33: a brief narrative on activities undertaken under subsection (3) of section 33 - (i) workshops, seminars and other interactions with public/experts/policy-makers/regulatory bodies on laws and polices relating to the real estate sector and for creating awareness on the same; (ii) papers and studies published for advocacy on laws and policies relating to the real estate sector and for creating awareness on the same; (iii) consultation papers published/placed on website of the Authority; (iv) analytical papers prepared and examined; (v) others.
N. Administration and establishment matters: (i) report of the Secretary; (ii) composition of the Authority; (iii) details of Chairperson and Members appointed in the year and of those who demitted office (iv) details of adjudicating officers appointed in the year and those who demitted office; (v) organizational structure; (vi) a tabular statement containing information on personnel in the Authority, category-wise: sanctioned posts, posts filled up, vacancies, appointments made in the year etc.
O. Experts and consultants engaged: details of number of experts and consultants appointed in the year and of those who demitted office.
P. Employee welfare measures, if any, beyond the regular terms and conditions of employment, undertaken by the Authority.
Q. Budget and Accounts: (i) budget estimates and revised estimates, under broad categories; (ii) receipts under broad categories in the Real Estate Regulatory Fund established under sub-section (1) of section 75; (iii) actual expenditure under broad categories; (iv) balance available in the Real Estate Regulatory Fund under sub-section (1) of section 75; (v) any other information.
R. International cooperation: A brief narrative of international cooperation, if any, undertaken by the Authority.
S. Capacity Building: A brief narrative of capacity building initiative undertaken including (i) number of employees (category wise and grade wise) trained in house with details of such programmes like content, duration and
faculty; (ii) number of employees (category wise and grade wise) trained by outside institutions (separately within Indian and outside India) with details of names of institutions and duration also to specify whether training was under internship, exchange programme, fellowships, study leave, special arrangements with foreign universities/institutions; (iii) expenditure of capacity building initiatives.
T. Ongoing programmes: A brief narrative of ongoing programmes.
U. Right to Information: A brief narrative of (i) Number of applications received by Central Public Information Officer/Assistant Central Public Information Officer seeking information under Right to Information Act; (ii) Number of applications for which information has been provided by Central Public Information Officer; (iii) Number of applications pending with Central Public Information Officer; (iv) Number of appeals filed before the First Appellate Authority against the order of Central Public Information Officer; (v) Number of appeals which have been disposed of by First Appellate Authority; (vi) Number of appeals pending with the First Appellate Authority; (vii) Number of applications/appeals not disposed of in the stipulated time frame.
Chairperson (Signature)
Member(s) (Signature)
SCHEDULE-I
(See Rule 3(2))
Rates of Registration Fee for Promoter
(Rs. per sq. meter)
| S. No. |
Category of uses |
Hyper/High Potential I & II |
Medium/Low Potential |
| 1. |
Residential/Industrial |
10 |
5 |
| 2. |
Commercial/Cyber Park |
20 |
10 |
Note. (1) Category of zones as defined in schedule mentioning rate of license fee in Rule 1976 of the Haryana Development and Regulation of Urban Area Act, 1975.
(2) In case of residential/industrial plotted colony, the rate would be applicable for gross area of the colony.
(3) In the case of Group Housing/Commercial/Cyber Park, rates are upto 100 FAR and would be proportionately higher for higher FAR.
SCHEDULE-II
(See rule 9(2) and 11(2)
Registration/renewal fee for Real Estate Agent
| Sr. No. |
Type of agent |
Registration fee |
Renewal fee |
| 1 |
For individual |
Rs. 25,000/- |
Rs. 5,000/- |
| 2 |
Other than individual |
Rs. 2,50,000/- |
Rs. 50,000/- |
SCHEDULE-III
(See rule 22(1) and 28(1)
Fee for filing complaint before the Authority and Appeal in the appellate Tribunal
1. Fee for filing complaint before the Authority: Rs. 1000/-
2. Fee for filing the appeal before the Appellate Tribunal: Rs. . 1000/-
3. Fee for every annexure Rs. 10/-
4. For every additional affidavit Rs. 20/-
Note. Separate fee of Rs. 1,000/shall be payable in case of filing of amended complaint/appeal.
ANNEXURE A
[See rule 8]
AGREEMENT FOR SALE
This Agreement for Sale ( Agreement ) executed on this ___ (Date) day of _____ (Month), 20 ____,
By and Between
[If the promoter is a company]
_______________ (CIN No. _______________), a company incorporated nder the provisions of the Companies Act, [1956 or 2013, as the case may be], having its registered office at__________________________ and its corporate office at_________________________ (PAN - _______________), represented by its authorized signatory ______________________________ (Aadhar No. _______________) authorized vide board resolution dated _______________ hereinafter referred to as the Promoter (which expression shall unless repugnant to the context or meaning thereof be deemed to mean and include its successor-in-interest, and permitted assigns).
[OR]
[If the promoter is a Partnership firm]
_______________, a partnership firm registered under the Indian Partnership Act, 1932, having its principal place of business at ______________________________, (PAN _______________), represented by its authorized Partner _________________________,(Aadhar No. _______________) authorized vide _______________, hereinafter referred to the Promoter (which expression shall unless repugnant to the context or meaning thereof be deemed to mean and include the partners or partner for the time being of the said firm, the survivor or survivors of them and their heirs, executors and administrators of the last surviving partner and his/her/their assigns).
[OR]
[If the promoter is an Individual]
Mr./Ms. _______________, (Aadhar No. _______________) son/daughter of_______________, aged about __________, residing at______________________, (PAN - _______________), hereinafter called the Promoter (which expression shall unless repugnant to the context or meaning thereof be deemed to mean and include his/her heirs, executors, administrators, successors-in-interest and permitted assigns).
AND
[If the Allottee is a company]
_______________, (CIN No. _______________) a company incorporated under the provisions of the Companies Act, [1956 or 2013, as the case may be], having its registered office at ______________________________, (PAN _______________), represented by its signatory, _______________, authorized (Aadhar No. _______________) duly authorized vide board resolution dated___________, hereinafter referred to as the Allottee (which expression shall unless repugnant to the context or meaning thereof be deemed to mean and include its successor-in-interest, and permitted assigns).
[OR]
[If the Allottee is a Partnership]
_______________, a partnership firm registered under the Indian Partnership Act, 1932, having its principal place of business at _______________, (PAN _______________), represented by its authorized partner, _______________, (Aadhar No. _______________) authorized vide _______________, hereinafter referred to as the Allottee (which expression shall unless repugnant to the context or meaning thereof be deemed to mean and include the partners or partner for the time being of the said firm, the survivor or survivors of them and their heirs, executors and administrators of the last surviving partner and his/her/their assigns).
[OR]
[If the Allottee is an Individual]
Mr./Ms. _______________, (Aadhar No. _______________) son/daughter of_______________, aged about _______________, residing at _______________, (PAN_______________), hereinafter called the Allottee (which expression shall unless repugnant to the context or meaning thereof be deemed to mean and include his/her heirs, executors, administrators, successors-in-interest and permitted A assigns).
[OR]
[If the Allottee is a HUF]
Mr. _______________, (Aadhar No. _______________) son of _________ aged about _________ for self and as the Karta of the Hindu Joint Mitakshara Family known as _______________HUF, having its place of business/residence at ______________________________, (PAN _______________), hereinafter referred to as the Allottee (which expression shall unless repugnant to the context or meaning thereof be deemed to mean and the members or member for the time being of the said HUF, and their respective heirs, executors, administrators and permitted assigns).
[Please insert details of other allottee(s), in case of more than one allottee]
The Promoter and Allottee shall hereinafter collectively be referred to as the Parties and individually as a Party .
DEFINITIONS:
For the purpose of this Agreement, unless the context otherwise requires,
(a) Act means the Real Estate (Regulation and Development) Act, 2016 (16 of 2016);
(b) Government means the Government of the State of Haryana;
(c) Rules means the Real Estate (Regulation and Development) Rules, 2017 for the State of Haryana;
(d) Section means a section of the Act.
WHEREAS:
A. The Promoter is the absolute and lawful owner of [khasra nos./survey nos.] [Please insert land details as per local laws] __________ totally admeasuring ________ square meters situated at ______in Tehsil & District _______________ ( Said Land ) vide sale deed(s) dated _______________registered as documents No. _________ at the office of the Sub-Registrar;
[OR]
_______________ ( Owner ) is the absolute and law full owner of [khasra nos./survey nos.] [Please insert land details as per local laws] _________ totally admeasuring _____ square meters situated at____ in Tehsil & District _______________ ( Said Land ) vide sale deed(s) dated___________ registered as documents no. _________ at the office of the Sub-Registrar. The Owner and the Promoter have entered into a [collaboration/development/joint development] agreement dated _________ registered as document no. _______ at the office of the Sub-Registrar;
B. The Said Land is earmarked for the purpose of a building [residential/commercial/industrial/IT/any other purpose] project, comprising ____ multistoried apartment(s)/building(s)/[insert any other components of the Projects] and the said project shall be known as _______________ ( Project );
[OR]
The Said Land is earmarked for the purpose of plotted development of a [residential/commercial/industrial/IT/any other purpose] project, comprising ________ plots/[insert any other components of the Projects] and the said project shall be known as _______________ ( Project ):
Provided that where the land is earmarked for any institutional development, the same shall be used for those purposes only and no commercial/residential development shall be permitted unless it has been approved by the competent authority;
C. The Promoter is fully competent to enter into this Agreement and all the legal formalities with respect to the right, title and interest of the Promoter regarding the Said Land on which Project is to be constructed have been complied with;
D. The _______________ [Please insert the name of the concerned competent authority] has granted the approval/sanction to develop the Project vide approval dated __________ bearing license/sanction No. ______________________________;
E. The Promoter has obtained approval on the layout plan/demarcation/zoning/site plan/building plan/or any requisite approval for the Project as the case may be, from______________________________ [Please insert the name of the concerned competent authority]. The Promoter agrees and undertakes that it shall not make any changes to these approved plans except in strict compliance with section 14 of the Act/any other laws of the State as applicable;
F. The Promoter has registered the Project under the provisions of the Act with the Haryana Real Estate Regulatory Authority at _______________ on ________ under registration No. _______________;
G. The Allottee had applied for residential apartment/commercial unit/IT unit/any other built up unit in the Project vide application no. ___________ dated _________ and has been allotted apartment no. __________ having carpet area of ______ square feet, on ____ floor in [tower/block/building] no. ________ ( Building ) along with stilt/basement parking No. (if applicable) ____________ admeasuring ___________ square feet in the _______________ [Please insert the location of the said parking], as permissible under the applicable law and right in the common areas ( Common Areas ) as defined under Rule 2(1)(f) of Rules, 2017 of the State (hereinafter referred to as the Apartment more particularly described in Schedule A and the floor plan of the apartment is annexed hereto and marked as Schedule B);
[OR]
The Allottee had applied for a plot in the Project vide application No. __________ dated _________ and has been allotted plot No. ___________ having area of ______ square meters and parking area (wherever applicable) admeasuring _________ [Area] (if applicable) in the __________ [Please insert the location of the said parking], as permissible under the applicable law and right in the common areas as per provisions of HDRU Act, 1975 (8 of 1975).
(hereinafter referred to as the Plot more particularly described in Schedule A);
H. The Parties have gone through all the terms and conditions of this Agreement and understood the mutual rights and obligations detailed herein;
I. [Please enter any additional disclosures/details];
J. The Parties hereby confirm that they are signing this Agreement with full knowledge of all the laws, rules, regulations, notifications, etc., applicable in the State and related to the Project;
K. The Parties, relying on the confirmations, representations and assurances of each other, do faithfully abide by all the terms, conditions and stipulations contained in this Agreement and all applicable laws, are now willing to enter into this Agreement on the terms and conditions appearing hereinafter;
L. In accordance with the terms and conditions of this Agreement and as mutually agreed upon by and between the Parties, the Promoter hereby agrees to sell and the Allottee(s) hereby agrees to purchase the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage (as the case may be) alongwith parking (if applicable) as specified in Para G.
NOW THEREFORE, in consideration of the mutual representations, covenants, assurances, promises and agreements contained herein and other good and valuable consideration, the Parties agree as follows:
1. TERMS:
1.1 Subject to the terms and conditions as detailed in this Agreement, the Promoter agrees to sell to the Allottee and the Allottee hereby agrees to purchase the Plot/Unit for Residential/Commercial/Industrial/IT/any other usage (as the case may be) alongwith parking (if applicable) as specified in Para G.
1.2 The Total Price for the built up Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage (as the case may be) alongwith parking (if applicable) based on the carpet area is Rs. _______________ (Rupees ______________________________only) ( Total Price ) (Give break up and description):
| Block/Building/Tower No. ______ Apartment |
Rate of Apartment per square feet |
| No. ______ |
|
| Type______ |
|
| Floor______ |
|
| Parking (if applicable) ______ |
|
| Total price (in rupees) |
__________________ |
[OR]
The Total Price of plot for Residential/Commercial/Industrial/IT/any other usage (as the case may be) alongwith parking (if applicable) as per approved demarcation/zoning plan (whichever is applicable) is Rs. ____________ (Rupees ______________________________ only) ( Total Price ) (Give break up and description):
| Plot No. ______ |
Rate of Plot per square meter |
| Block No. ______ |
|
| Area of the Plot (in square meter) ______ |
|
| Parking (if applicable) ______ |
|
| Total price (in rupees) |
__________________ |
Explanation:
(i) The Total Price as mentioned above includes the booking amount paid by the allottee to the Promoter towards the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage (as the case may be) alongwith parking (if applicable);
(ii) The Total Price as mentioned above includes Taxes (GST and Cess or any other taxes/fees/charges/levies etc. which may be levied, in connection with the development/construction of the Project(s)) paid/payable by the Promoter up to the date of handing over the possession of the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage (as the case may be) alongwith parking (if applicable) to the allottee(s) or the competent authority, as the case may be, after obtaining the necessary approvals from competent authority for the purposes of such possession:
Provided that, in case there is any change/modification in the taxes/charges/fees/levies etc., the subsequent amount payable by the allottee to the promoter shall be increased/decreased based on such change/modification:
Provided further, if there is any increase in the taxes/charges/fees/levies etc. after the expiry of the scheduled date of completion of the project as per registration with the Authority, which shall include the extension of registration, if any, granted to the said project by the Authority, as per the Act, the same shall not be charged from the allottee;
(iii) The Promoter shall periodically intimate in writing to the Allottee, the amount payable as stated in (i) above and the Allottee shall make payment demanded by the Promoter within the time and in the manner specified therein. In addition, the Promoter shall provide to the Allottee(s) the details of the taxes/fees/charges/levies etc. paid or demanded along with the acts/rules/notifications together with dates from which such taxes/fees/charges/levies etc. have been imposed or become effective;
(iv) The Total Price of Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage (as the case may be) alongwith parking (if applicable) includes recovery of price of land, development/construction of [not only of the Apartment/Unit/Plot] but also of the Common Areas (if applicable), internal development charges, infrastructure augmentation charges, external development charges, taxes/fees/levies etc., cost of providing electric wiring, electrical connectivity to the apartment, lift, water line and plumbing, finishing with paint, marbles, tiles, doors, windows, fire detection and fire fighting equipment in the common areas, maintenance charges as per para 11 etc. and includes cost for providing all other facilities, amenities and specifications to be provided within the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage (as the case may be) alongwith parking (if applicable) in the Project.
1.3 The Total Price is escalation-free, save and except increases which the Allottee hereby agrees to pay, due to increase on account of development charges payable to the competent authority and/or any other increase in charges which may be levied or imposed by the competent authority from time to time. The Promoter undertakes and agrees that while raising a demand on the Allottee for increase in development charges, cost/charges/fees/levies etc. imposed by the competent authorities, the Promoter shall enclose the said notification/order/rule/regulation to that effect along with the demand letter being issued to the Allottee, which shall only be applicable on subsequent payments. Provided that if there is any new imposition or increase of any development charges after the expiry of the scheduled date of completion of the project as per registration with the Authority, which shall include the extension of registration, if any, granted to the said project by the Authority, as per the Act, the same shall not be charged from the allottee.
1.4 The Allottee(s) shall make the payment as per the payment plan set out in Schedule C ( Payment Plan ).
1.5 The Promoter may allow, in its sole discretion, a rebate for early payments of installments payable by the Allottee by discounting such early payments @ % per annum for the period by which the respective installment has been preponed. The provision for allowing rebate and such rate of rebate shall not be subject to any revision/withdrawal, once granted to an Allottee by the Promoter unless agreed upon by the allottee(s).
1.6 It is agreed that the Promoter shall not make any additions and alterations in the sanctioned building plans and specifications and the nature of fixtures, fittings and amenities described herein at Schedule D and Schedule E (which shall be in conformity with the advertisement, prospectus etc., on the basis of which sale is effected) in respect of the apartment, plot or building, as the case may be, without the previous written consent of the Allottee as per the provisions of the Act and Rules made thereunder or as per approvals/instructions/guidelines of the competent authorities. Provided that, the Promoter may make such minor additions or alterations as may be required by the Allottee, or such minor changes or alterations as per the provisions of the Act and Rules made thereunder or as per approvals/instructions/guidelines of the competent authorities.
1.7 [Applicable in case of an apartment/unit] The Promoter shall confirm to the carpet area that has been allotted to the Allottee after the construction of the Building/Unit, as the case may be, is complete and the occupation certificate/part occupation (as the case may be) is granted by the competent authority, by furnishing details of the changes, if any, in the carpet area. The total price payable for the carpet area shall be recalculated upon confirmation by the Promoter. If there is reduction in the carpet area then the Promoter shall refund the excess money paid by Allottee within 90 days with annual interest at the rate prescribed in the Rules, from the date when such an excess amount was paid by the Allottee. If there is any increase in the carpet area, which is not more than five percent of the carpet area of the apartment, allotted to the Allottee, the Promoter may demand that from the Allottee as per the next milestone of the Payment Plan as provided in Schedule C. All these monetary adjustments shall be made at the same rate per square feet as agreed in para 1.2 of this Agreement.
[OR]
[Applicable in case of a plot] The Promoter shall confirm the area of a plot as per approved demarcation-cum-zoning plan that has been allotted to the Allottee(s) after the development of the plotted area alongwith essential services [as mandated by Rules and Regulation of competent authority] is complete. The Promoter shall inform the allottee about any details of the changes, if any, in the area. The total price payable for the area shall be recalculated upon confirmation by the Promoter. If there is reduction in the area then the Promoter shall refund the excess money paid by Allottee within 90 days with annual interest at the rate prescribed in the Rules, from the date when such an excess amount was paid by the Allottee. If there is any increase in the area, which is not more than five percent of the area of the plot, allotted to the Allottee, the Promoter may demand that from the Allottee as per the next milestone of the Payment Plan as provided in Schedule C. All these monetary adjustments shall be made at the same rate per square meter as agreed in para 1.2 of this Agreement
1.8 Subject to para 9.3 the Promoter agrees and acknowledges, the Allottee shall have the right to the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage (as the case may be) alongwith parking (if applicable) as mentioned below:
(i) The Allottee shall have exclusive ownership of the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage (as the case may be) alongwith parking (if applicable);
(ii) The Allottee shall also have a right in the Common Areas as provided under Rule 2(1)(f) of Rules, 2017 of the State. The Allottee(s) shall use the Common Areas along with other occupants, maintenance staff etc., without causing any inconvenience or hindrance to them. It is clarified that the promoter shall hand over the common areas to the association of allottees/competent authorities after duly obtaining the occupation certificate/part occupation certificate/part completion/completion certificate from the competent authority, as the case may be as provided under Rule 2(1)(f) of Rules, 2017 of the State;
(iii) The Allottee has the right to visit the project site to assess the extent of development of the project and his Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage (as the case may be).
1.9 The Promoter agrees to pay all outstanding payments before transferring the physical possession of the apartment to the Allottees, which it has collected from the Allottees, for the payment of such outstanding (including land cost, ground rent, municipal or other local taxes/charges/levies etc., charges for water or electricity, maintenance charges, including mortgage loan and interest on mortgages or other encumbrances and such other liabilities payable to competent authorities, banks and financial institutions, which are related to the project). If the Promoter fails to pay all or any of the outstanding(s) collected by it from the Allottees or any liability, mortgage loan and interest thereon before transferring the apartment to the Allottees, the Promoter agrees to be liable, even after the transfer of the property, to pay such outstanding(s) and penal charges, if any, to the authority or person to whom they are payable and be liable for the cost of any legal proceedings which may be taken therefor by such authority or person.
1.10 The Allottee has paid a sum of Rs. ____________ (Rupees________________________________________________ only) as booking amount being part payment towards the Total Price of the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage (as the case may be) alongwith parking (if applicable) at the time of application; the receipt of which the Promoter hereby acknowledges and the Allottee hereby agrees to pay the remaining price of the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage (as the case may be) alongwith parking (if applicable) as prescribed in the Payment Plan [Schedule C] as may be demanded by the Promoter within the time and in the manner specified therein:
Provided that if the allottee delays in payment towards any amount which is payable, he shall be liable to pay interest at the rate prescribed in the Rule 15 of HRERA Rules, 2017.
2. MODE OF PAYMENT:
Subject to the terms of the Agreement and the Promoter abiding by the construction/development milestones, the Allottee shall make all payments, on written demand by the Promoter, within the stipulated time as mentioned in the Payment Plan [Schedule C] through A/c Payee cheque/demand draft/bankers cheque or online payment (as applicable) in favour of' __________________ payable at __________________.
3. COMPLIANCE OF LAWS RELATING TO REMITTANCES:
3.1 The Allottee, if residing outside India, shall be solely responsible for complying with the necessary formalities as laid down in Foreign Exchange Management Act, 1999, Reserve Bank of India Act, 1934 and the Rules and Regulations made thereunder or any other statutory amendment(s) modification(s) made thereof and all other applicable laws including that of remittance of payment acquisition/sale/transfer of immovable properties in India etc. and provide the Promoter with such permission, approvals which would enable the Promoter to fulfill its obligations under this Agreement. Any refund, transfer of security, if provided in terms of the Agreement shall be made in accordance with the provisions of Foreign Exchange Management Act, 1999 or any other statutory enactments or amendments thereof and the Rules and Regulations of the Reserve Bank of India or any other applicable law. The Allottee understands and agrees that in the event of any failure on his/her part to comply with the applicable guidelines issued by the Reserve Bank of India, he/she may be liable for any action under the Foreign Exchange Management Act, 1999 or other laws as applicable, as amended from time to time.
3.2 The Promoter accepts no responsibility in regard to matters specified in para 3.1 above. The Allottee shall keep the Promoter fully indemnified and harmless in this regard. Whenever there is any change in the residential status of the Allottee subsequent to the signing of this Agreement, it shall be the sole responsibility of the Allottee to intimate the same in writing to the Promoter immediately and comply with all necessary formalities as specified and under the applicable laws. The Promoter shall not be responsible towards any third party making payment/remittances on behalf of any Allottee and such third party shall not have any right in the application/allotment of the said Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage (as the case may be) applied for herein in any way and the Promoter shall be issuing the payment receipts in favour of the Allottee(s) only.
4. ADJUSTMENT/APPROPRIATION OF PAYMENTS:
The Allottee authorizes the Promoter to adjust/appropriate all payments made by him/her under any head(s) of dues against lawful outstanding of the allottee against the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage (as the case may be) alongwith parking (if applicable), if any, in his/her name and the Allottee undertakes not to object/demand/direct the Promoter to adjust his payments in any manner.
5. TIME IS ESSENCE:
The Promoter shall abide by the time schedule for completing the project as disclosed at the time of registration of the project with the Authority and towards handing over the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage (as the case may be) alongwith parking (if applicable) to the Allottee(s) and the common areas to the association of allottees or the competent authority, as the case may be, as provided under Rule 2(1)(f) of Rules, 2017.
6. CONSTRUCTION/DEVELOPMENT OF THE PROJECT:
The Allottee has seen the proposed layout plan/demarcation-cum-zoning/site plan/building plan, specifications, amenities, facilities, etc. depicted in the advertisement/brochure/agreement/website (as the case may be) regarding the project(s) where the said Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage (as the case may be) alongwith parking (if applicable) is located and has accepted the floor/site plan, payment plan and the specifications, amenities, facilities, etc. [annexed along with this Agreement] which has been approved by the competent authority, as represented by the Promoter.
The Promoter shall develop the Project in accordance with the bye-laws such as Haryana Building Code, 2017, FAR, density norms, provisions prescribed, approved plans, terms and condition of the license/allotment as well as registration of RERA, etc. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent Authorities and shall also strictly abide by the provisions and norms prescribed by the __________________ [Please insert the relevant State laws] and shall not have an option to make any variation/alteration/modification in such plans, other than in the manner provided under the Act and Rules made thereunder or as per approvals/instructions/guidelines of the competent authorities, and any breach of this term by the Promoter shall constitute a material breach of the Agreement.
7. POSSESSION OF THE PLOT/UNIT/APARTMENT FOR RESIDENTIAL/COMMERCIAL/INDUSTRIAL/IT/ANY OTHER USAGE (AS THE CASE MAY BE):
7.1 Schedule for possession of the said Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage - The Promoter agrees and understands that timely delivery of possession of the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage (as the case may be) alongwith parking (if applicable) to the Allottee(s) and the common areas to the association of allottees or the competent authority, as the case may be, as provided under Rule 2(1)(f) of Rules, 2017, is the essence of the Agreement.
The Promoter assures to hand over possession of the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage (as the case may be) alongwith parking (if applicable) as per agreed terms and conditions unless there is delay due to force majeure , Court orders, Government policy/guidelines, decisions affecting the regular development of the real estate project. If, the completion of the Project is delayed due to the above conditions, then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage (as the case may be).
The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure and above mentioned conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee, the entire amount received by the Promoter from the allottee within ninety days. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
7.2 (A) Procedure for taking possession of Plot - The Promoter, upon obtaining the approved demarcation-cum-zoning plan/provision of services by the colonizer/promoter, duly certifying/part completion certificate, as the case may be, in respect of plotted colony shall offer in writing the possession of the plot within three months from the date of above, to the Allottee(s) as per terms of this Agreement.
The Promoter agrees and undertakes to indemnify the Allottee(s) in case of failure of fulfillment of any of the provisions, formalities, documentation on part of the Promoter. The promoter shall provide a copy (on demand) of approved demarcation-cum-zoning plan/provision of services by the colonizer/part completion certificate in respect of plotted development [Residential/Commercial/Industrial/IT Colony/any other usage (as the case may be) alongwith parking (if applicable)] at the time of conveyance of the same. The Allottee(s), after taking possession, agree(s) to pay the maintenance charges and holding charges as determined by the Promoter/association of allottees/competent authority, as the case may be.
(B) Procedure for taking possession of built-up Unit/Apartment - The Promoter, upon obtaining the occupation certificate or part thereof of building blocks in respect of Group Housing/Commercial/IT Colony/Industrial/any other usage (as the case may be) alongwith parking (if applicable) shall offer in writing the possession of the unit/apartment within three months from the date of above approval, to the Allottee(s) as per terms of this Agreement.
The Promoter agrees and undertakes to indemnify the Allottee in case of failure of fulfillment of any of the provisions, formalities, documentation on part of the Promoter. The promoter shall provide copy (on demand) of occupation certificate or part thereof in respect of Group Housing/Commercial/IT Colony/Industrial/any other usage (as the case may be) alongwith parking (if applicable) at the time of conveyance of the same. The Allottee(s), after taking possession, agree(s) to pay the maintenance charges and holding charges as determined by the Promoter/association of allottees/competent authority, as the case may be.
7.3 Failure of Allottee to take Possession of Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage - Upon receiving a written intimation from the Promoter as per para 7.2, the Allottee shall take possession of the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage from the Promoter by executing necessary indemnities, undertakings and such other documentation as prescribed in this Agreement, and the Promoter shall give possession of the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage to the allottee as per terms and condition of the agreement.
In case the Allottee fails to comply with the essential documentation, undertaking, etc. or fails to take possession within the time provided in para 7.2, such Allottee shall continue to be liable to pay maintenance charges and holding charges as specified in para 7.2.
7.4 Possession by the Allottee - After obtaining the occupation certificate of the building blocks in respect of Group Housing colony/Commercial colony/IT Colony or approved Zoning-cum-Demarcation Plan/provision of the services by the colonizer/promoter, duly certifying/part completion, in respect of a plotted colony, as the case may be and handing over the physical possession of the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage alongwith parking (if applicable) to the Allottee(s), it shall be the responsibility of the Promoter to hand over the necessary documents and plans, and common areas to the association of allottees or the competent authority, as the case may be as provided under Rule 2(1)(f) of Rules, 2017.
7.5 Cancellation by Allottee - The Allottee shall have the right to cancel/withdraw his allotment in the Project as provided in the Act:
Provided that where the allottee proposes to cancel/withdraw from the project without any fault of the promoter, the promoter herein is entitled to forfeit the booking amount paid for the allotment and interest component on delayed payment (payable by the customer for breach of agreement and non payment of any due payable to the promoter). The rate of interest payable by the allottee to the promoter shall be the State Bank of India highest marginal cost of lending rate plus two percent. The balance amount of money paid by the allottee shall be returned by the promoter to the allottee within ninety days of such cancellation.
7.6 Compensation The Promoter shall compensate the Allottee in case of any loss caused to him due to defective title of the land, on which the project is being developed or has been developed, in the manner as provided under the Act and the claim for interest and compensation under this provision shall not be barred by limitation provided under any law for the time being in force.
Except for occurrence of a force majeure , Court orders. Government policy/guidelines, decisions, if the promoter fails to complete or is unable to give possession of the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage alongwith parking (if applicable).
(i) in accordance with the terms of this Agreement, duly completed by the date specified in para 7.1; or
(ii) due to discontinuance of his business as a developer on account of suspension or revocation of the registration under the Act; or for any other reason; the Promoter shall be liable, on demand to the allottees, in case the Allottee wishes to withdraw from the Project, without prejudice to any other remedy available, to return the total amount received by him in respect of the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage, with interest at the rate prescribed in the Rules including compensation in the manner as provided under the Act within ninety days of it becoming due.
Provided that if the Allottee does not intend to withdraw from the Project, the Promoter shall pay the Allottee interest at the rate prescribed in the Rules for every month of delay, till the offer of the possession of the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage, which shall be paid by the promoter to the allottee within ninety days of it becoming due.
8. REPRESENTATIONS AND WARRANTIES OF THE PROMOTER:
The Promoter hereby represents and warrants to the Allottee as follows:
(i) The [Promoter] has absolute, clear and marketable title with respect to the said Land; the requisite rights to carry out development upon the said Land and absolute, actual, physical and legal possession of the said Land for the Project;
(ii) The Promoter has lawful rights and requisite approvals from the competent Authorities to carry out development of the Project;
(iii) There are no encumbrances upon the said Land or the Project;
[in case there are any encumbrances on the land provide details of such encumbrances including any rights, title, interest and name of party in or over such land]
(iv) All approvals, licenses, sanctions and permission issued by the competent authorities with respect to the Project(s) or phase(s), as the case may be, as well as for the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage being sold to the allottee(s) are valid and subsisting and have been obtained by following due process of law.
Further, the Promoter has been and shall, at all times, remain to be in compliance with all applicable laws in relation to the Project(s) or phase(s), as the case may be, as well as for the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage and for common areas as provided under Rule 2(1)(f) of Rules, 2017;
(v) The Promoter has the right to enter into this Agreement and has not committed or omitted to perform any act or thing, whereby the right, title and interest of the Allottee created herein, may prejudicially be affected;
(vi) The Promoter has not entered into any agreement for sale and/or development agreement or any other agreement/arrangement with any person or party with respect to the said Land, including the Project and the said Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage which will, in any manner, affect the rights of Allottee(s) under this Agreement;
(vii) The Promoter confirms that the Promoter is not restricted in any manner whatsoever from selling the said Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage to the Allottee(s) in the manner contemplated in this Agreement;
(viii) At the time of execution of the conveyance deed the Promoter shall handover lawful, vacant, peaceful, physical possession of the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage alongwith parking (if applicable) to the Allottee(s), common areas to the association of allottees or the competent authority, as the case may be, as provided under Rule 2(1)(f) of Rules, 2017;
(ix) The Schedule Property is not the subject matter of any HUF and that no part thereof is owned by any minor and/or no minor has any right, title and claim over the Schedule Property;
(x) The Promoter has duly paid and shall continue to pay and discharge all governmental dues, rates, charges and taxes and other monies, levies, impositions, premiums, damages and/or penalties and other outgoings, whatsoever, payable with respect to the said project to the competent Authorities till the offer of possession of plot/apartment/commercial unit/IT unit has been issued, as the case may be and as per the provisions of the Haryana Development and Regulation of Urban Areas Act, 1975, rules thereof-equipped with all the specifications, amenities, facilities as per the agreed terms and conditions and common areas as provided under Rule 2(1)(f) of Rules, 2017;
(xi) No notice from the Government or any other local body or authority or any legislative enactment, government ordinance, order, notification (including any notice for acquisition or requisition of the said property) has been received by or served upon the Promoter in respect of the said Land and/or the Project.
9. EVENTS OF DEFAULTS AND CONSEQUENCES:
9.1 Subject to the force majeure , Court orders. Government policy/guidelines, decisions, the Promoter shall be considered under a condition of Default, in the following events:
(i) Promoter fails to provide ready to move in possession of the developed Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage alongwith parking (if applicable) to the Allottee within the time period specified in para 7.1 or fails to complete the project within the stipulated time disclosed at the time of registration of the project with the Authority. For the purpose of this para, ready to move in possession shall mean that the Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage shall be in a habitable condition which is complete in all respects including the provision of all specifications, amenities and facilities, as agreed to between the parties, and for which occupation certificate or part thereof has been issued by competent authority.
[OR]
For the purposes of developed plot, it shall mean the plot, having provision of water supply, sewerage, electricity, roads or any other amenities approved in the demarcation-cum-zoning plan, essential for habitable environment (as per guidelines of the competent authority) and for the same the promoter has obtained demarcation-cum-zoning plan/part completion/completion certificate, as the case may be;
(ii) Discontinuance of the Promoter's business as a developer on account of suspension or revocation of his registration under the provisions of the Act or the rules or regulations made thereunder.
9.2 In case of Default by Promoter under the conditions listed above, Allottee is entitled to the following:
(i) Stop making further payments to Promoter as demanded by the Promoter. If the Allottee stops making payments, the Promoter shall correct the situation by completing the construction/development milestones and only thereafter the Allottee be required to make the next payment without any interest for the period of such delay; or
(ii) The Allottee shall have the option of terminating the Agreement in which case the Promoter shall be liable to refund the entire money paid by the Allottee under any head whatsoever towards the purchase of the plot/unit/apartment, along with interest at the rate prescribed in the Rules within ninety days of receiving the termination notice:
Provided that where an Allottee does not intend to withdraw from the project or terminate the Agreement, he shall be paid, by the promoter, interest at the rate prescribed in the Rules, for every month of delay till the handing over of the possession of the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage alongwith parking (if applicable), which shall be paid by the promoter to the allottee within ninety days of it becoming due.
9.3 The Allottee shall be considered under a condition of Default, on the occurrence of the following events:
(i) In case the Allottee fails to make payments for two consecutive demands made by the Promoter as per the Payment Plan annexed hereto, despite having been issued notice in that regard the allottee shall be liable to pay interest to the promoter on the unpaid amount at the rate prescribed in the Rules;
(ii) In case of Default by Allottee under the condition listed above continues for a period beyond ninety days after notice from the Promoter in this regard, the Promoter may cancel the allotment of the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT/any other usage alongwith parking (if applicable) in favour of the Allottee and refund the money paid to him by the allottee by forfeiting the booking amount paid for the allotment and interest component on delayed payment (payable by the customer for breach of agreement and non payment of any due payable to the promoter). The rate of interest payable by the allottee to the promoter shall be the State Bank of India highest marginal cost of lending rate plus two percent. The balance amount of money paid by the allottee shall be returned by the promoter to the allottee within ninety days of such cancellation. On such default, the Agreement and any liability of the promoter arising out of the same shall thereupon, stand terminated. Provided that, the promoter shall intimate the allottee about such termination at least thirty days prior to such termination.
10. CONVEYANCE OF THE SAID UNIT/APARTMENT/PLOT:
The promoter on receipt of total price of the plot as per 1.2, shall execute a conveyance deed preferably within three months but not later than six months from possession and convey the title of the plot for which possession is granted to the allottee.
[OR]
The promoter, on receipt of total price of Unit/Apartment for Residential/Commercial/Industrial/IT Colony/any other usage alongwith parking (if applicable), shall execute a conveyance deed in favour of allottee(s) preferably within three months but not later than six months from possession:
Provided that, the unit/apartment/plot is equipped with all the specifications, amenities, facilities as per the agreed terms and conditions and common areas as provided under Rule 2(1)(f) of Rules, 2017. However, in case, the Allottee fails to deposit the stamp duty and/or registration charges, other ancillary charges within the period mentioned in the notice, the Allottee authorizes the Promoter to withhold registration of the conveyance deed in his/her favour till such stamp duty, registration charges, other ancillary charges are paid by the Allottee to the Promoter.
11. MAINTENANCE OF THE SAID BUILDING/APARTMENT/PROJECT:
The Promoter shall be responsible to provide and maintain essential services in the Project till the taking over of the maintenance of the project by the association of allottees or competent authority, as the case may be, upon the issuance of the occupation certificate/part thereof, part completion certificate/completion certificate of the project, as the case may be. The cost of such maintenance has been included in the Total Price of the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT Colony/any other usage.
In case, the allottee/association of allottees fails to take possession of the said essential services as envisaged in the agreement or prevalent laws governing the same, then in such a case, the promoter or the developer has right to recover such amount as spent on maintaining such essential services beyond his scope.
12. DEFECT LIABILITY:
It is agreed that in case any structural defect or any other defect in workmanship, quality or provision of services or any other obligations of the Promoter as per the agreement for sale relating to such development is brought to the notice of the Promoter within a period of 5 (five) years by the Allottee from the date of handing over possession, it shall be the duty of the Promoter to rectify such defects without further charge, within ninety days, and in the event of Promoter's failure to rectify such defects within such time, the aggrieved Allottees shall be entitled to receive appropriate compensation in the manner as provided under the Act:
Provided that, the promoter shall not be liable for any such structural/architectural defect induced by the allottee(s), by means of carrying out structural or architectural changes from the original specifications/design.
13. RIGHT TO ENTER THE UNIT/APARTMENT/PLOT FOR REPAIRS AND MAINTENANCE WORKS:
The Promoter/maintenance agency/association of allottees/competent authority shall have rights of access of Common Areas, parking spaces for providing necessary maintenance services and the allottee(s) agrees to permit the association of allottees and/or maintenance agency/competent authority to enter into the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT Colony/any other usage after giving due notice and entering the said premises during the normal working hours, unless the circumstances warrant otherwise, with a view to rectify such defect(s).
14. USAGE:
Use of Basement and Service Areas: The basement(s) and service areas, if any, as located within the ______________________________ (project name), shall be earmarked for purposes such as parking spaces and services including but not limited to electric sub-station, transformer, DG set rooms, underground water tanks, pump rooms, maintenance and service rooms, fire fighting pumps and equipment's etc. and other permitted uses as per sanctioned plans. The Promoter/Allottee(s) shall not be permitted to use the services areas and the basements in any manner whatsoever, other than those earmarked as parking spaces, and the same shall be reserved for use by the association of allottees formed by the Allottees, maintenance agencies/competent authority for rendering maintenance services.
15. GENERAL COMPLIANCE WITH RESPECT TO THE UNIT/APARTMENT/PLOT:
15.1 Subject to para 12 above, the Allottee shall, after taking possession, be solely responsible to maintain the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT Colony/any other usage alongwith parking (if applicable) at his/her own cost, in good repair and condition and shall not do or suffer to be done anything in or to the Building, or the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT Colony/any other usage alongwith parking (if applicable), or the staircases, lifts, common passages, corridors, circulation areas, atrium or the compound which may be in violation of any laws or rules of any authority or change or alter or make additions to the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT Colony/any other usage alongwith parking (if applicable) and keep the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT Colony/any other usage alongwith parking (if applicable), its walls and partitions, sewers, drains, pipe and appurtenances thereto or belonging thereto, in good and tenantable repair and maintain the same in a fit and proper condition and ensure that the support, shelter etc. of the Building is not in any way damaged or jeopardized.
15.2 The Allottee/Association of allottees further undertakes, assures and guarantees that he/she would not put any sign-board/name-plate, neon light, publicity material or advertisement material etc. on the face/facade of the Building or anywhere on the exterior of the Project, buildings therein or Common Areas. The Allottees shall also not change the colour scheme of the outer walls or painting of the exterior side of the windows or carry out any change in the exterior elevation or design. Further the Allottee/Association of allottees shall not store any hazardous or combustible goods in the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT Colony/any other usage and parking (if applicable) or place any heavy material in the common passages or staircase of the Building. The promoter/allottees/association of allottees shall ensure that they will not create any hindrance by way of locking, blocking, parking or any other manner in right of passage or access or common areas which otherwise are available for free access. The Allottee/Association of allottees shall also not remove any wall, including the outer and load bearing wall of the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT Colony/any other usage and parking (if applicable), as the case may be.
15.3 The Allottee/Association of allottees shall plan and distribute its electrical load in conformity with the electrical systems installed by the Promoter and thereafter the association of allottees and/or maintenance agency appointed by association of allottees/competent authority. The Allottee shall be responsible for any loss or damages arising out of breach of any of the aforesaid conditions.
16. COMPLIANCE OF LAWS, NOTIFICATIONS ETC. BY PARTIES:
The Parties are entering into this Agreement for the allotment of a Plot/Unit/Apartment for Residential/Commercial/Industrial/IT Colony/any other usage alongwith parking (if applicable) with the full knowledge of all laws, rules, regulations, notifications applicable in the State and related to the project.
17. ADDITIONAL CONSTRUCTIONS:
The Promoter undertakes that it has no right to make additions or to put up additional structure(s) anywhere in the Project after the building plan, layout plan, sanction plan and specifications, amenities and facilities has been approved by the competent authority(ies) and disclosed, except for guidelines/permissions/directions or sanctions by competent authority.
18. PROMOTER SHALL NOT MORTGAGE OR CREATE A CHARGE:
After the Promoter executes this Agreement he shall not mortgage or create a charge on the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT Colony/any other usage and parking (if applicable) and if any such mortgage or charge is made or created then notwithstanding anything contained in any other law for the time being in force, such mortgage or charge shall not affect the right and interest of the Allottee who has taken or agreed to take such Plot/Unit/Apartment for Residential/Commercial/Industrial/IT Colony/any other usage and parking (if applicable).
19. APARTMENT OWNERSHIP ACT (OF THE RELEVANT STATE):
The Promoter has assured the Allottees that the project in its entirety is in accordance with the provisions of the relevant Acts, Rules and Regulations/bye laws, instructions/guidelines and decisions of competent authority prevalent in the State. The Promoter hereby is showing the detail of various compliance of above as applicable:
Details of approvals/compliances to be provided:
(A) ________________________;
(B) ________________________;
(C) ________________________;
(D) ________________________;
(E) ________________________;
20. BINDING EFFECT:
By just forwarding this Agreement to the Allottee by the Promoter, does not create a binding obligation on the part of the Promoter or the Allottee until, firstly, the Allottee signs and delivers this Agreement with all the schedules along with the payments due as stipulated in the Payment Plan within 30 (thirty) days from the date of receipt by the Allottee. Secondly, the allottee and the promoter have an obligation to execute the agreement and also register the said agreement as per the provision of the relevant Act of the State.
If the Allottee(s) fails to execute and deliver to the Promoter, this Agreement within 30 (thirty) days from the date of its receipt by the Allottee and further execute the said agreement and register the said agreement, as per intimation by the Promoter, then the Promoter shall serve a notice to the Allottee for rectifying the default, which if not rectified within sixty days from the date of its receipt by the Allottee, application of the Allottee shall be treated as cancelled and all sums deposited by the Allottee in connection therewith including the booking amount shall be returned to the Allottee without any interest or compensation whatsoever. If, however, after giving an fair opportunity to the allottee to get this agreement executed, the allottee does not come forward or is incapable of executing the same, then in such a case, the promoter has an option to forfeit ten percent of booking amount.
21. ENTIRE AGREEMENT:
This Agreement, along with its schedules, constitutes the entire Agreement between the Parties with respect to the subject matter hereof and supersedes any and all understandings, any other agreements, allotment letter, correspondences, arrangements whether written or oral, if any, between the Parties in regard to the said Plot/Unit/Apartment for Residential/Commercial/Industrial/IT Colony/any other usage and parking (if applicable).
22. RIGHT TO AMEND:
This Agreement may only be amended through written consent of the Parties concerned in said agreement.
23. PROVISIONS OF THIS AGREEMENT APPLICABLE ON ALLOTTEE(S)/SUBSEQUENT ALLOTTEE(S):
It is clearly understood and so agreed by and between the Parties hereto that all the provisions contained herein and the obligations arising hereunder in respect of the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT Colony/any other usage and parking (if applicable) and the Project shall equally be applicable to and enforceable against and by any subsequent Allottee(s) of the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT Colony/any other usage and parking (if applicable) in case of a transfer, as the said obligations go along with the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT Colony/any other usage and parking (if applicable) for all intents and purposes.
24. WAIVER NOT A LIMITATION TO ENFORCE:
24.1 The Promoter may, at its sole option and discretion, without prejudice to its rights as set out in this Agreement, waive the breach by the Allottee(s) in not making payments as per the Payment Plan [Annexure C] including waiving the payment of interest for delayed payment. It is made clear and so agreed by the Allottee(s) that exercise of discretion by the Promoter in the case of one Allottee shall not be construed to be a precedent and/or binding on the Promoter to exercise such discretion in the case of other Allottees.
24.2 Failure on the part of the Parties to enforce at any time or for any period of time, the provisions hereof shall not be construed to be a waiver of any provisions or of the right thereafter to enforce each and every provision.
25. SEVERABILITY:
If any provision of this Agreement shall be determined to be void or unenforceable under the Act or the Rules and Regulations made thereunder or under other applicable laws, such provisions of the Agreement shall be deemed amended or deleted in so far as reasonably inconsistent with the purpose of this Agreement and to the extent necessary to conform to Act or the Rules and Regulations made thereunder or the applicable law, as the case may be, and the remaining provisions of this Agreement shall remain valid and enforceable as applicable at the time of execution of this Agreement.
26. METHOD OF CALCULATION OF PROPORTIONATE SHARE WHEREVER REFERRED TO IN THE AGREEMENT:
Wherever in this Agreement, it is stipulated that the Allottee has to make any payment, in common with other Allottee(s) in Project, the same shall be the proportion which the area/carpet area of the Plot/Unit/Apartment for Residential/Commercial/Industrial/IT Colony/any other usage and parking (if applicable) bears to the total area/carpet area of all the Unit/Apartments/Plots in the Project.
27. FURTHER ASSURANCES:
Both Parties agree that they shall execute, acknowledge and deliver to the other such instruments and take such other actions, in additions to the instruments and actions specifically provided for herein, as may be reasonably required in order to effectuate the provisions of this Agreement or of any transaction contemplated herein or to confirm or perfect any right to be created or transferred hereunder or pursuant to any such transaction.
28. PLACE OF EXECUTION:
The execution of this Agreement shall be complete only upon its execution by the Promoter through its authorized signatory at the Promoter's Office, or at some other place, which may be mutually agreed between the Promoter and the Allottee, in __________________ after the Agreement is duly executed by the Allottee and the Promoter or simultaneously with the execution, the said Agreement shall be registered as per provisions of the relevant State Act at __________________. Hence this Agreement shall be deemed to have been executed at __________________.
29. NOTICES:
That all notices to be served on the Allottee and the Promoter as contemplated by this Agreement shall be deemed to have been duly served if sent to the Allottee or the Promoter by Registered Post at their respective addresses specified below:
__________________Name of Allottee
__________________ (Allottee Address)
M/s __________________Promoter name
__________________ (Promoter Address)
It shall be the duty of the Allottee and the Promoter to inform each other of any change in address subsequent to the execution of this Agreement in the above address by Registered Post failing which all communications and letters posted at the above address shall be deemed to have been received by the promoter or the Allottee, as the case may be.
30. JOINT ALLOTTEES:
That in case there are Joint Allottees, all communications shall be sent by the Promoter to the Allottee whose name appears first and at the address given by him/her which shall for all intents and purposes to consider as properly served on all the Allottees.
31. SAVINGS:
Any application letter, allotment letter, agreement, or any other document signed by the allottee, in respect of the unit/apartment, plot or building, as the case may be, prior to the execution and registration of this Agreement for Sale for such apartment, plot or building, as the case may be, shall not be construed to limit the rights and interests of the allottee under the Agreement for Sale or under the Act or the rules or the regulations made thereunder.